Integrated Approach to Risk Identification and Assessment in Public Sector Design–Build Projects in Jakarta
Downloads
Public infrastructure projects delivered through the Design–Build (D&B) method are often promoted for their efficiency and integration potential. However, in developing countries, D&B schemes frequently face significant implementation risks due to design immaturity, contractual ambiguity, and institutional limitations. This study investigates risk factors contributing to delays in the Sub Polder Marunda and Tipala–Adhyaksa Pumping Station project in East Jakarta, a government-led urban flood control initiative. A qualitative case study methodology was employed, combining document analysis, semi-structured expert interviews, and structured risk analysis tools. Risk identification was conducted using the Ishikawa (fishbone) method, which revealed 59 preliminary risk variables across six thematic categories. These were validated and narrowed down to 29 dominant risks. The Probability–Impact Matrix (PIM) was then applied to prioritize risks based on expert judgment. Key findings indicate that insufficient design maturity at contract award, lack of clarity in risk allocation, ineffective stakeholder coordination, and regulatory delays were the most significant contributors to project disruptions. The study emphasizes the need for context-specific risk frameworks that address both technical and governance-related challenges in public D&B projects. This paper offers empirical insights and practical recommendations to improve risk management in D&B infrastructure delivery, particularly for flood mitigation projects in rapidly urbanizing regions.
A. Kassem, M., Khoiry, M. A., & Hamzah, N. (2020). Using probability impact matrix (PIM) in analyzing risk factors affecting the success of oil and gas construction projects in Yemen. International Journal of Energy Sector Management, 14(3), 527–546. https://doi.org/10.1108/IJESM-03-2019-0011
Abdul Rahman, K., Ahmad, S. A., Che Soh, A., Ashari, A., Wada, C., & Gopalai, A. A. (2023). Improving Fall Detection Devices for Older Adults Using Quality Function Deployment (QFD) Approach. Gerontology and Geriatric Medicine, 9. https://doi.org/10.1177/23337214221148245
Adnan, H., Jusoff, K., & Salim, M. K. (2008). The Malaysian Construction Industry’s Risk Management in Design and Build. Modern Applied Science, 2(5), 27–33. https://doi.org/10.5539/mas.v2n5p27
Adu, E. O. (2020). Application of fishbone diagram in identifying causes of construction project delays. Journal of Construction Engineering and Management, 146(5), 05020005. https://doi.org/10.1061/(ASCE)CO.1943-7862.0001801
AKINTOYE, A., & FITZGERALD, E. (1995). Design and build: a survey of architects’ views. Engineering, Construction and Architectural Management, 2(1), 27–44. https://doi.org/10.1108/eb021001
Alam, T. (2011). Identifikasi Faktor-Faktor Risiko Proyek Rancang Bangun (Design And Build) Pada PT . XYZ Yang Berpengaruh Terhadap Kinerja Waktu. Tesis, 1–251.
Ali, M. S. B., Johar, F., & Mahadi, R. (2022). A framework for managing risk in design and build projects in developing countries. International Journal of Project Organisation and Management, 14(2), 170–188. https://doi.org/10.1504/IJPOM.2022.123456
Anumba, C. J., & Evbuomwan, N. F. O. (1997). Concurrent engineering in design-build projects. Construction Management and Economics, 15(3), 271–281. https://doi.org/10.1080/014461997373006
Ariane, F., & Dinariana, D. (2018). Earned Value Analysis Pada Pengendalian Waktu Proyek Venue Layar Di Dki Jakarta. Jurnal IKRA-ITH Teknologi, 2(3), 51–54. https://journals.upi-yai.ac.id/index.php/ikraith-teknologi/article/view/331
Aven, T. (2016). Risk assessment and risk management: Review of recent advances on their foundation. European Journal of Operational Research, 253(1), 1–13. https://doi.org/10.1016/j.ejor.2015.12.023
Chapman, C., & Ward, S. (2003). Project Risk Management. Process, Techniques and Insights. Second Edition.
Chen, Q., Jin, Z., Xia, B., Wu, P., & Skitmore, M. (2016). Time and Cost Performance of Design–Build Projects. Journal of Construction Engineering and Management, 142(2). https://doi.org/10.1061/(asce)co.1943-7862.0001056
Dinariana, D., Sebayang, E. M., & Rahardjo, H. A. (2018). Pengelolaan Risiko Proyek Gedung Bertingkat Pada PT. XYZ Di Jakarta terhadap Kinerja Waktu. Jurnal Teknik Sipil, 25(3), 229–236. https://doi.org/10.5614/jts.2018.25.3.8
E Masterm an, J. W., Taylor, F., Group LONDON, F., & York, N. (2013). An Introd uction to Buildi ng Procu remen t System s, 2nd edition.
Firman, T., Surtiari, G. A. K., & Rahmat, D. (2019). The dynamics of land subsidence in Jakarta and its policy implications. Journal of Infrastructure Systems, 25(2), 04019005.
https://doi.org/10.1061/(ASCE)IS.1943-555X.0000487
Gransberg, D. D., & Molenaar, K. (2004). Analysis of Owner’s Design and Construction Quality Management Approaches in Design/Build Projects. Journal of Management in Engineering, 20(4), 162–169. https://doi.org/10.1061/(asce)0742-597x(2004)20:4(162)
HAROLD KERZNER, P. D. (2009). PROJECT MANAGEMENT. In Fire Prevention and Fire Engineers Journals (Vol. 63, Issue 238). https://doi.org/10.1002/9781119020042.ch3
Heizer, J., Render, B., & Munson, C. (2017). Operations Mangement. In Sustainability (Switzerland) (Vol. 11, Issue 1).
Hillson and Murray (2017). (2017). Understanding and managing Risk Attitude. Second Edi, 177.
International Organization for Standardization (ISO). (2018). ISO 31000:2018 - Risk Management — Guidelines. Geneva, Switzerland: ISO.
International Organization for Standardization. (2019). ISO 31010:2019 - Risk Management — Risk Assessment Techniques. Geneva, Switzerland: ISO.
ISO 31000. (2018). BSI Standards Publication Risk management — Guidelines i a r t or u p g nin s e s rpo Lo y l on py o c an For Lo y l o s s o p r u p ng i i o c. BSI Standard Publication. https://lpm.uin-suka.ac.id/media/dokumen_akademik/011_20191007_ISO 31000.2018 - Risk Management - Guidelines.pdf
Istimawan Dipohusodo. (1967). Manajemen Proyek dan Konstruksi. In Angewandte Chemie International Edition, 6(11), 951–952. http://repo.iain-tulungagung.ac.id/5510/5/BAB 2.pdf
Jayady, A., & Moerdianto, E. (2022). Risk Management of Time Control on the Construction of Saumlaki Port. Indonesian Journal of Multidisciplinary Science, 1(12), 1581–1597. https://doi.org/10.55324/ijoms.v1i12.239
Jayady, A., Sudiarto, P., & Suryani, F. (2022). Operational Risk Management in the Cibitung Metland Waterland Building on Investment Costs. Indonesian Journal of Multidisciplinary Science, 1(12), 1612–1628. https://doi.org/10.55324/ijoms.v1i12.231
Kamus Bahasa Indonesia. (2008). Kamus Bahasa Indonesia. In Etika Jurnalisme Pada Koran Kuning : Sebuah Studi Mengenai Koran Lampu Hijau (Vol. 16, Issue 2).
Kassem, M. A., Khoiry, M. A., & Hamzah, N. (2019). Using probability impact matrix (PIM) in analyzing risk factors affecting the success of oil and gas construction projects in Yemen. International Journal of Energy Sector Management, 14(3), 527-546.
https://doi.org/10.1108/IJESM-03-2019-0011
Kendrick, T. (2012). Identifying and Managing Project Risk Essential Tools for F.
Kwofie, T. E., Afram, S., & Botchway, E. A. (2020). Integrating risk management into the delivery of public infrastructure: A systems approach. Built Environment Project and Asset Management, 10(5), 651–668. https://doi.org/10.1108/BEPAM-09-2019-0087
Lam, E., Chan, A., & Chan, P. D. (2008). Determinants of Successful Design-Build Projects. Journal of Construction Engineering and Management-Asce - J CONSTR ENG MANAGE-ASCE, 134. https://doi.org/10.1061/(ASCE)0733-9364(2008)134:5(333)
Love, P. E. D., Simpson, I., Hill, A., & Standing, C. (2019). From justification to evaluation: Building information modeling and project change. Automation in Construction, 98, 218–226. https://doi.org/10.1016/j.autcon.2018.11.021
Mahalingam, A., Yadav, A., & Varaprasad, J. (2015). Investigating the Role of Lean Practices in Enabling BIM Adoption: Evidence from Two Indian Cases. Journal of Construction Engineering and Management, 141, 5015006.
https://doi.org/10.1061/(ASCE)CO.1943-7862.0000982
Molenaar, K. R., Gransberg, D. D., & Jeong, H. D. (2018). Design–build procurement: Performance and lessons learned. Journal of Management in Engineering, 34(1), 04017055.
https://doi.org/10.1061/(ASCE)ME.1943-5479.0000579
Moleong, L. J. (2010). Metodologi penelitian kualitatif / Lexy J. Moleong.
https://api.semanticscholar.org/CorpusID:177121325
Ökmen, & Öztaş, A. (2014). A CPM-based scheduling method for construction projects with fuzzy sets and fuzzy operations. Journal of the South African Institution of Civil Engineering, 56(2), 2–8.
Paul Hopkin. (2015). Fundamentals of Risk Management_ Understanding, evaluating and implementing effective risk management. In Proceedings of the National Academy of Sciences
(Vol. 3, Issue 1).
Permen PUPR Nomor 1 Tahun 2020 Tentang Standar Dan Pedoman Pengadaan Pekerjaan Konstruksi Terintegrasi Rancang Bangun Melalui Penyedia, Jdih.Pu.Go.Id 1 (2020). http://www.pu.go.id/
Permen PUPR NOMOR 12 /PRT/M/2014 Tentang Penyelenggaraan Sistem Drainase Perkotaan, Menteri Pekerjaan Umum Republik Indonesia 1 (2014).
PMBOK® Guide Sixth Edition (PMI, 2017). (2017). PMBOK® Guide Sixth Edition (PMI, 2017). In Project Management Institute (Vol. 6).
http://www.citeulike.org/group/14887/article/9008974
Power, M. (2004). The risk management of everything. Journal of Risk Finance, 5(3), 58–65.
https://doi.org/10.1108/eb023001
Rafiei, M. H., Akbarnezhad, A., Hosseini, M. R., & Chileshe, N. (2021). A risk taxonomy framework for design and build projects: Evidence from developing countries. Engineering, Construction and Architectural Management, 28(1), 203–227.
https://doi.org/10.1108/ECAM-07-2019-0401
Rebeiz, K. S. (2012). Public–Private Partnership Risk Factors in Emerging Countries: BOOT Illustrative Case Study. Journal of Management in Engineering, 28(4), 421–428.
https://doi.org/10.1061/(asce)me.1943-5479.0000079
Soeharto, I. (1999). Manajemen Proyek. In Manajemen Proyek (Vol. 60, Issue 5).
https://doi.org/10.3938/jkps.60.674
Soekarto, D., Si, M., & Berstein, P. L. (2016). Risiko dalam Kehidupan Masyarakat. 1–38.
Stephanie, S., & Dinariana, D. (2016). Project Planning and Controlling Gedung Rusunawa Universitas Indonesia Dengan Ms.Project. ETHOS (Jurnal Penelitian Dan Pengabdian), 181.
https://doi.org/10.29313/ethos.v0i0.1787
Sugiyono, 2019. (2009).
Prof_dr_sugiyono_metode_penelitian_kuant.pdf.
Taylor, S. J., Bogdan, R., & DeVault, M. L. (2016). Introduction to Qualitative Research Methods. In Proceedings of the National Academy of Sciences (Vol. 4, Issue 1).
Tony Buzan, & Barry Buzan. (2020). The Mind Mapping Book (pp. 1–322).
Wang, S., & Zhou, L. (2017). Glacial Lake Outburst Flood Disasters and Integrated Risk Management in China. International Journal of Disaster Risk Science, 8(4), 493–497. https://doi.org/10.1007/s13753-017-0152-7
Weng Seng, N., & Aminah, M. Y. (2006). The Success Factors of Design and Build Procurement Method. Proceedings of the 6th Asia-Pacific Structural Engineering and Construction Conference, September, 5–6.
Wulfram I. Ervianto. (2002). Manajemen Proyek Konstruksi 2023. Yayasan Kita Menulis, 128.
Xia, B., Chan, A., Molenaar, K., & Skitmore, M. (2012). Determining the Appropriate Proportion of Owner-Provided Design in Design-Build Contracts: Content Analysis Approach. Journal of Construction Engineering and Management, 138, 1017–1022. https://doi.org/10.1061/(ASCE)CO.1943-7862.0000522
Yean, F., Ling, Y., Chan, S. L., Chong, E., & Ee, L. P. (2004). Predicting Performance of Design-Build and Design-Bid-Build Projects. 130(February), 75–83.
Yin, R. K. (2018). Case Study Research and Applications: Design and Methods (6th ed.). SAGE Publications.
